BOARD OF COUNTY
COMMISSIONERS
NASSAU COUNTY, FLORIDA
INVITATION TO BID
NOTICE IS HEREBY GIVEN that the Board of County Commissioners of Nassau County, Florida invites sealed proposals for:
ON-CALL ELECTRICAL
SERVICES
SOLICITATION NO.
NC23-052-ITB
ELECTRONIC BIDS
RECEIVED UNTIL OCTOBER 18, 2023 BY 10:00 AM
For detailed information regarding the due date and requirements for this solicitation, please visit the Nassau County website at https://pbsystem.planetbids.com/portal/49083/portal-home. Solicitation information and documents can be obtained free-of-charge via the County’s vendor portal.
ATTEST:
JOHN A. CRAWFORD
EX-OFFICIO CLERK
KLYNT FARMER
CHAIRMAN
BOARD OF COUNTY
COMMISSIONSER
NASSAU COUNTY, FLORIDA
FNL 1T 09-13-2023
#779387
-----------
BOARD OF COUNTY
COMMISSIONERS
NASSAU COUNTY, FLORIDA
INVITATION TO BID
NOTICE IS HEREBY GIVEN that the Board of County Commissioners of Nassau County, Florida invites sealed proposals for:
FURNISH, DELIVER, AND INSTALL METAL BUILDING
SOLICITATION NO.
NC23-054-ITB
ELECTRONIC BIDS
RECEIVED UNTIL OCTOBER 18, 2023 BY 10:00 AM
For detailed information regarding the due date and requirements for this solicitation, please visit the Nassau County website at https://pbsystem.planetbids.com/portal/49083/portal-home. Solicitation information and documents can be obtained free-of-charge via the County’s vendor portal.
ATTEST:
JOHN A. CRAWFORD
EX-OFFICIO CLERK
KLYNT FARMER
CHAIRMAN
BOARD OF COUNTY
COMMISSIONERS
NASSAU COUNTY, FLORIDA
FNL 1T 09-13-23
#779390
-----------
NOTICE OF INTENTION TO CONSIDER
ENACTMENT OF
ORDINANCE
NOTICE is hereby given that the Board of County Commissioners of Nassau County, Florida, at a meeting to be held on Monday, the 25th day of September, 2023 at 6:00 P.M., or as soon thereafter as the matter may be heard, in the Commission Chambers, located at the James S. Page Governmental Complex, 96135 Nassau Place, Yulee, Florida, intends to consider for adoption the following proposed Ordinance:
ORDINANCE NO. 2023-_
AN ORDINANCE OF THE BOARD OF COUNTY COMMISSIONERS OF NASSAU COUNTY, FLORIDA, AMENDING CHAPTER 1 ADMINISTRATION. AT ARTICLE I. IN GENERAL. TO REVISE SECTION 1-15. INVESTMENT OF SURPLUS PUBLIC FUNDS. TO CONFORM WITH SECTION 218.415, FLORIDA STATUTES, LOCAL GOVERNMENT INVESTMENT POLICIES; PROVIDING FOR ADOPTION OF AN INVESTMENT POLICY BY RESOLUTION AND IN CONFORMANCE WITH SECTION 218.415, FLORIDA STATUTES; FURTHER PROVIDING FOR CODIFICATION; CONFLICTING PROVISIONS; PROVIDING FOR SEVERABILITY CLAUSE AND AN EFFECTIVE DATE.
Copies of the Ordinance are available at the County Managers Office, 96135 Nassau Place, Suite 1, Yulee, Florida 32097 Monday through Friday, 8:30 a.m. through 5:00 p.m., except legal holidays.
THE PUBLIC IS INVITED TO BE PRESENT AND BE HEARD. In accordance with Florida Statute 286.0105: If any person decides to appeal any decision made of this Board or Committee with respect to any matter considered at this scheduled meeting or hearing, the person will need a record of the proceedings, and for such purpose the person may need to ensure that a verbatim record of the proceedings is made, which record includes the testimony and evidence upon which the appeal is to be based.
The Board of County Commissioners may continue hearings on this matter.
ATTEST:
/s/ JOHN A. CRAWFORD
Its: Ex-Officio Clerk
BOARD OF COUNTY
COMMISSIONERS OF
NASSAU COUNTY, FLORIDA
BY: /s/ KLYNT A. FARMER
Its: Chairman
In accordance with the Americans with Disabilities Act, persons needing a reasonable accommodation to participate in this proceeding should contact the County Managers Office at contact@nassaucountyfl.com, 96135 Nassau Place, Suite 1, Yulee, FL 32097, Phone No. 904-530-6010, not later than seventy-two (72) hours prior to the proceeding. If you are hearing or voice impaired, please call the Florida Relay Service at 711 or toll free at 1-800-955-8771 (TTY).
FNL 1T 09-13-2023
#779413
-----------
PUBLIC NOTICE
This public notice is to solicit Pre-Qualification applications from General Contractors as per the State Requirements for Educational Facilities (SREF, 2014), Chapter 4.1 (1)(a) and Nassau County School District Administrative Rule 6.08 as follows:
(1) Pre-qualification of General Contractors for Educational Facilities Construction. A Board shall pre-qualify contractors for a certain period or for a specific project. The intent of this section is to prescribe uniform requirements for pre-qualification of contractors.
(a) Criteria. Contractors shall be pre-qualified by a board on the basis of the following criteria and such other criteria as the board may adopt.
1. Proof that the contractor is licensed to engage in the business of contracting in the State of Florida by the Construction Industry Licensing Board and, which authorizes the contractor to supervise the work within the scope of the construction project.
2. Evidence that the applicant has financial resources to start up and follow through on projects and to respond to damages in case of default as shown by written verification of bonding capacity equal to or exceeding the amount of any project for which the contractor seeks pre-qualification. The written verification must be submitted by a licensed surety company rated excellent (A- or better) in the current A.M. Best Guide and qualified to do business within the state. In the absence of such written verification, the board may require the applicant to submit any audited financial information necessary to evaluate an applicants financial ability to perform the project and to respond to damages in the event of default.
3. Evidence of experience with construction techniques, trade standards, quality workmanship, project scheduling, cost control, management of projects, and knowledge of building codes for similar, or less cost or lesser scope projects as shown by the successful completion within the past five (5) years of at least two (2) other projects of similar size.
4. Evidence of satisfactory resolution of claims filed by or against the contractor asserted on projects of the same or similar size within the five (5) years preceding the submission of the application. Any claim against a contractor shall be deemed to have been satisfactorily resolved if final judgment is rendered in favor of the contractor or any final judgment rendered against the contractor is satisfied within ninety (90) days of the date the judgment becomes final.
5. Type of work for which the contractor is licensed. Evidence of timely completion of projects of similar scope and size. Include any liquidated damages that may have been or could have been assessed on these projects.
The School Board of Nassau County is calling for proposals for PRE-QUALIFYING OF GENERAL CONTRACTORS for the purpose of bidding on a construction Project at Callahan Elementary School
PROJECT: The Contractor(s) selected for this pre-qualification will be eligible to bid on the assigned project. Parent Pick-up Lane Extension at Callahan Elementary School.
Pre-Qualification packets are available in the office of the Director of Facilities of the Nassau County School District, 86334 Goodbread Road, Yulee, Florida 32097. Interested parties may pick up packets or request an electronic file between the hours of 8:00 a.m. and 2:00 p.m., Monday through Friday.
Original Completed Packets must be delivered to the same location no later than 2:00 p.m., October 12, 2023.
For the School Board of Nassau County
Jeffrey L. Bunch
Director of Facilities
FNL 3T 09-13-20-27-2023
#779436
-----------
NOTICE OF INTENTION TO CONSIDER
ENACTMENT OF
ORDINANCE
NOTICE is hereby given that the Board of County Commissioners of Nassau County, Florida, at a meeting to be held on Monday, the 25th day of September, 2023 at 6:00 P.M., or as soon thereafter as the matter may be heard, in the Commission Chambers, located at the James S. Page Governmental Complex, 96135 Nassau Place, Yulee, Florida, intends to consider for adoption the following proposed Ordinance:
ORDINANCE NO. 2023-___
AN ORDINANCE OF THE BOARD OF COUNTY COMMISSIONERS OF NASSAU COUNTY, FLORIDA, AMENDING CHAPTER 1 ADMINISTRATION. AT ARTICLE VII. - PURCHASING POLICY. IN ORDER TO AMEND THE PURCHASING POLICY DEFINITIONS; THE PURCHASING CATEGORIES; THE PURCHASE ORDER REQUIREMENTS; THE COMPETITIVE AND ALTERNATIVE PURCHASING METHODS INCLUDING EXEMPTIONS; THE PROVISIONS RELATING TO CONTRACTS, CHANGE ORDERS, TASK ORDERS, WORK AUTHORIZATIONS AND AMENDMENTS; LOCAL VENDOR PREFERENCE; USE OF DESIGN-BUILD FOR COUNTY PROJECTS; AND TO PROVIDE ENTIRELY NEW SUBSECTIONS ENTITLED PROCUREMENT CODE OF ETHICS AND PROTEST PROCEDURES; IN ADDITION PROVIDING FOR CODIFICATION; CONFLICTING PROVISIONS; PROVIDING FOR SEVERABILITY CLAUSE AND AN EFFECTIVE DATE.
Copies of the Ordinance are available at the County Managers Office, 96135 Nassau Place, Suite 1, Yulee, Florida 32097 Monday through Friday, 8:30 a.m. through 5:00 p.m., except legal holidays.
THE PUBLIC IS INVITED TO BE PRESENT AND BE HEARD. In accordance with Florida Statute 286.0105: If any person decides to appeal any decision made of this Board or Committee with respect to any matter considered at this scheduled meeting or hearing, the person will need a record of the proceedings, and for such purpose the person may need to ensure that a verbatim record of the proceedings is made, which record includes the testimony and evidence upon which the appeal is to be based.
The Board of County Commissioners may continue hearings on this matter.
ATTEST:
/s/ JOHN A. CRAWFORD
Its: Ex-Officio Clerk
BOARD OF COUNTY
COMMISSIONERS OF
NASSAU COUNTY, FLORIDA
BY: /s/ KLYNT A. FARMER
Its: Chairman
In accordance with the Americans with Disabilities Act, persons needing a reasonable accommodation to participate in this proceeding should contact the County Managers Office at contact@nassaucountyfl.com, 96135 Nassau Place, Suite 1, Yulee, FL 32097, Phone No. 904-530-6010, not later than seventy-two (72) hours prior to the proceeding. If you are hearing or voice impaired, please call the Florida Relay Service at 711 or toll free at 1-800-955-8771 (TTY).
FNL 1T 09-13-2023
#779441
-----------
IN THE CIRCUIT COURT, FOURTH JUDICIAL CIRCUIT, IN AND FOR
NASSAU COUNTY, FLORIDA
PROBATE DIVISION
File No. 45-2023-CP-443
Division A
IN RE: ESTATE OF
RICHARD R. ROENISCH,
Deceased.
NOTICE TO CREDITORS
(Summary Administration)
TO ALL PERSONS HAVING CLAIMS OR DEMANDS AGAINST THE ABOVE ESTATE:
You are hereby notified that a Petition For Summary Administration has been filed in the estate of Richard R. Roenisch, deceased, File Number 45-2023-CP-443, in the Circuit Court for NASSAU County, Florida, Probate Division, the address of which is 76347 Veterans Way, Yulee, Florida 32097; that the decedent's date of death was August 21, 2023;
ALL INTERESTED PERSONS ARE NOTIFIED THAT:
All creditors of the estate of the decedent and persons having claims or demands against the estate of the decedent must file their claims with this court WITHIN THE TIME PERIODS SET FORTH IN FLORIDA STATUTES SECTION 733.702. ALL CLAIMS AND DEMANDS NOT SO FILED WILL BE FOREVER BARRED. NOTWITHSTANDING ANY OTHER APPLICABLE TIME PERIOD, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT'S DATE OF DEATH IS BARRED.
The date of first publication of this Notice is September 13th, 2023.
DOUGLAS A. OBERDORFER, Esquire
Attorney for Petitioners
Florida Bar Number: 0139092
432 East Monroe Street
Jacksonville, Florida 32202
Telephone: (904) 354-5454
Fax: (904) 350-9803
E-Mail:
doug@oberdorferlaw.com
E-Mail:
service@oberdorferlaw.com
FNL 2T 09-13-20-2023
#779448
-----------
BOARD OF COUNTY
COMMISSIONERS
NASSAU COUNTY, FLORIDA
INVITATION TO BID
NOTICE IS HEREBY GIVEN that the Board of County Commissioners of Nassau County, Florida invites sealed proposals for:
NASSAU CROSSING PARK SOCCER FIELD SOD AND
IRRIGATION
INSTALLATION SERVICES
SOLICITATION NO.
NC23-038R-RFP
ELECTRONIC BIDS
RECEIVED UNTIL OCTOBER 18, 2023 BY 10:00 AM
For detailed information regarding the due date and requirements for this solicitation, please visit the Nassau County website at https://pbsystem.planetbids.com/portal/49083/portal-home. Solicitation information and documents can be obtained free-of-charge via the County’s vendor portal.
ATTEST:
JOHN A. CRAWFORD
EX-OFFICIO CLERK
KLYNT FARMER
CHAIRMAN
BOARD OF COUNTY
COMMISSIONERS
NASSAU COUNTY, FLORIDA
FNL 1T 09-13-2023
#779466
-----------
BOARD OF COUNTY
COMMISSIONERS
NASSAU COUNTY, FLORIDA
INVITATION TO BID
NOTICE IS HEREBY GIVEN that the Board of County Commissioners of Nassau County, Florida invites sealed proposals for:
MOWING, LANDSCAPE MAINTENANCE, AND OTHER RELATED SERVICES
SOLICITATION NO.
NC23-055-ITB
ELECTRONIC BIDS RECEIVED UNTIL OCTOBER 18, 2023 BY 10:00 AM
For detailed information regarding the due date and requirements for this solicitation, please visit the Nassau County website at https://pbsystem.planetbids.com/portal/49083/portal-home. Solicitation information and documents can be obtained free-of-charge via the County’s vendor portal.
ATTEST:
JOHN A. CRAWFORD
EX-OFFICIO CLERK
KLYNT FARMER
CHAIRMAN
BOARD OF COUNTY
COMMISSIONERS
NASSAU COUNTY, FLORIDA
FNL 1T 09-13-2023
#779577
-----------
IN THE CIRCUIT COURT OF THE FOURTH JUDICIAL
CIRCUIT
IN AND FOR NASSAU
COUNTY FLORIDA
Case No.: 2022-CP-0157
IN RE: ESTATE OF
JANET GAUDIELLO,
Deceased.
NOTICE TO CREDITORS
The administration of the estate of JANET GAUDIELLO, deceased, whose date of death was February 13, 2022 is pending in the Circuit Court for Nassau County, Florida, Probate Division, the address of which is 76347 Veterans Way, Yulee, Florida 32097.
The names and addresses of the personal representative and the personal representative's
attorneys are set forth below.
All creditors of the decedent and other persons having claims or demands against decedent's estate on whom a copy of this notice is required to be served must file their claims with this court WITHIN THE LATER OF 3 MONTHS AFTER THE TIME OF THE FIRST PUBLICATION OF THIS NOTICE OR 30 DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and persons having claims or demands against decedent's estate must file their claims with this court WITHIN 3 MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS NOT SO FILED WILL BE FOREVER BARRED.
The date of first publication of this notice is the 13th day of September, 2023.
Personal Representative:
/s/ Christopher VonZech
Christopher VonZech
405 3rd Avenue
Satsuma, FL 32189
Attorney for Personal Representative:
/s/ Arthur I. Jacobs
Arthur I. Jacobs, Esq.
Jacobs Scholz & Wyler, LLC
Gateway Blvd., Suite 201-I
Fernandina Beach, Florida 32034
jacobsscholzlaw@comcast.net
FNL 2T 09-13-20-2023
#779583
-----------
NOTICE UNDER FICTITIOUS
NAME LAW PURSUANT TO
SECTION 865.09,
FLORIDA STATUTES
NOTICE IS HEREBY GIVEN that the undersigned, desiring to engage in business under the fictitious name of MOON RIVER PIZZA located at 925 S 14th Street in the County of Nassau, in the city of Fernandina Beach, Florida 32034 intends to register the said name with the Division of Corporations of the Florida Department of State, Tallahassee, Florida.
Dated at Fernandina Beach, this 7th day of September 2023.
Andrew J Bottorff
Shrewfit LLC
FNL 1T 09-13-2023
#779603
------------
IN THE CIRCUIT COURT, FOURTH
JUDICIAL CIRCUIT, IN AND FOR
NASSAU COUNTY, FLORIDA.
PROBATE DIVISION
CASE NO.: 2023-CP-000377
DIVISION: A
IN RE: THE ESTATE OF:
BETTY HOPPER,
Deceased
NOTICE TO CREDITORS
The administration of the estate of Betty Hopper, deceased, whose date of death was June 27, 2023, is pending in the Circuit Court for Nassau County, Florida, Probate Division, the address of which is Nassau County Courthouse, 76347 Veterans Way, Yulee, FL 32097. The name and addresses of the personal representative and the personal representative's attorney are set forth below.
All creditors of the decedent and other persons having claims or demands against decedent's estate on whom a copy of this notice is required to be served must file their claims with this court ON OR BEFORE THE LATER OF 3 MONTHS AFTER THE TIME OF THE FIRST PUBLICATION OF THIS NOTICE OR 30 DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and other persons having claims or demands against decedent's estate must file their claims with this court WITHIN 3 MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS NOT FILED WITHIN THE TIME PERIODS SET FORTH IN FLORIDA STATUTES SECTION 733.702 WILL BE FOREVER BARRED.
NOTWITHSTANDING THE TIME PERIODS SET FORTH ABOVE, ANY CLAIM FILED TWO (2) YEARS OR MORE AFTER THE DECEDENT'S DATE OF DEATH IS BARRED.
The date of first publication of this notice is September 13th, 2023
Cleve A. Hopper
Petitioner
35199 Welcome Lane
Callahan, FL 32011
MICHAEL L. EDWARDS
Florida Bar No. 248622
432 East Monroe Street
Jacksonville, FL 32202
(904)350-9800/FAX 350-9803
edwardsmllaw@att.net
Attorney for Petitioner
FNL 2T 09-13-20-2023
#779609
-----------
IN THE CIRCUIT COURT OF THE FOURTH JUDICIAL
CIRCUIT,
IN AND FOR NASSAU
COUNTY, FLORIDA
PNC Bank, N.A.
Plaintiff,
vs.
Kenneth L. Thompson, et al.
Defendants. Case No.: 22CA000343AXYX
Division: Civil
NOTICE OF SALE
Notice is hereby given that on November 30, 2023 at 11:30 AM, the below named Clerk of Court will offer by electronic sale at www.nassau.realforeclose.com the following described real property:
Tract 16, Brantley Farms, according to plat thereof recorded in Plat Book 5, page 97, of the public records of Nassau County, Florida.
Commonly known as: 273159 Murrhee Road, Hilliard, FL 32046
Any person claiming an interest in the surplus from this sale, if any, other than the property owner as of the date of the lis pendens must file a claim before the clerk reports the surplus as unclaimed.
The sale is being held pursuant to the Final Judgment of Foreclosure, entered on August 29, 2023, in Civil Case No. 22CA000343AXYX, pending in the Circuit Court in Nassau County, Florida.
JOHN A. CRAWFORD
CLERK OF THE CIRCUIT COURT
NASSAU COUNTY, FLORIDA
Shawn L. Taylor (Florida Bar No.: 0103176)
Valerie N. Edgecombe (Florida Bar No.: 10193)
Michael E. Carleton (Florida Bar No.: 1007924)
Jasmin Hernandez (Florida Bar No.: 1044494)
Manley Deas Kochalski LLC
P. O. Box 165028
Columbus, OH 43216-5028
Telephone: 407-404-5266
Telecopier: 614-220-5613
Primary:
stateefiling@manleydeas.com
Secondary:
sef-sltaylor@manleydeas.com
Attorney for Plaintiff
FNL 2T 09-13-20-2023
#779625
-----------
NOTICE OF PUBLIC SALE:
BILL'S TOWING gives notice that on 09/29/2023 at 8:30 AM the vehicles(s) may be sold by public sale at 425 SOUTH 8TH STREET FERNANDINA BEACH FL 32034 to satisfy the lien for the amount owed on each vehicle for any recovery, towing, or storage services charges and administrative fees allowed pursuant to Florida statute 713.78.
JN8AF5MR2FT504683
2015 NISS
This notification is Published in NEWSLEADER on 09/13/2023
FNL 1T 09/13/2023
#779629
-----------
NOTICE OF INTENTION TO CONSIDER ENACTMENT OF AN ORDINANCE
NOTICE IS HEREBY GIVEN that the Nassau County Board of County Commissioners will conduct a public hearing on Monday, September 25, 2023 at 6:00 PM, or soon thereafter to consider the following proposed Ordinance. The public hearing will be held at the James S. Page Governmental Complex, 96135 Nassau Place, Yulee, Florida 32097.
ORDINANCE NO. 2023 - ___
AN ORDINANCE OF THE BOARD OF COUNTY COMMISSIONERS OF NASSAU COUNTY, FLORIDA, AMENDING CHAPTER 34 COMPREHENSIVE IMPACT FEE ORDINANCE, NASSAU COUNTY CODE OF ORDINANCES, AMENDING SECTION 34-83 PROVIDING AN IMPACT FEE EXEMPTION FOR REDEVELOPMENT TINY HOME DEVELOPMENTS; PROVIDING FOR CODIFICATION; PROVIDING FOR CONFLICTING PROVISIONS; PROVIDING FOR SEVERABILITY; AND PROVIDING AN EFFECTIVE DATE.
All interested parties are invited to attend the public hearings and to be heard. Copies of the proposed Ordinance and supporting information are available for inspection in the Planning Department, 96161 Nassau Place, Yulee, FL 32097. Comments may also be directed in writing to the Planning Department, e-mailed to planning@nassaucountyfl.com, or received by telephone at (904) 530-6320. All comments will become part of the record in this matter and subject to Floridas public records law.
In accordance with the Americans With Disabilities Act, persons needing a reasonable accommodation to participate in this proceeding should contact the County Managers Office at contact@nassaucountyfl.com, 96135 Nassau Place, Suite 1, Yulee, FL 32097, Phone No. 904-530-6010, not later than seventy-two (72) hours prior to the proceeding. If you are hearing or voice impaired, please call the Florida Relay Service at 711 or toll free at 1-800-955-8771 (TTY).
THE PUBLIC IS INVITED TO BE PRESENT AND BE HEARD. IF A PERSON DECIDES TO APPEAL ANY DECISION MADE BY THE BOARD, AGENCY OR COMMISSION WITH RESPECT TO ANY MATTER CONSIDERED AT SUCH MEETING OR HEARING HE/SHE WILL NEED A RECORD OF THE PROCEEDINGS AND FOR THAT PURPOSE, MAY NEED TO ENSURE THAT A VERBATIM RECORD OF THE PROCEEDINGS IS MADE, WHICH RECORD INCLUDES THE TESTIMONY AND EVIDENCE UPON WHICH APPEAL IS TO BE BASED
The Board of County Commissioners may continue hearings on this matter.
Klynt Farmer, Chair
Board of County
Commissioners
John A. Crawford,
Ex-Officio Clerk
FNL 1T 09-13-2023
#779663
-----------
NOTICE OF INTENTION TO CONSIDER ENACTMENT OF AN ORDINANCE
NOTICE IS HEREBY GIVEN that the Nassau County Board of County Commissioners will conduct a public hearing on Monday, September 25, 2023 at 6:00 PM, or soon thereafter to consider the following proposed Ordinance. The public hearing will be held at the James S. Page Governmental Complex, 96135 Nassau Place, Yulee, Florida 32097.
ORDINANCE NO. 2023 - ___
AN ORDINANCE OF THE BOARD OF COUNTY COMMISSIONERS OF NASSAU COUNTY, FLORIDA, AMENDING CHAPTER 36 MOBILITY FEES, NASSAU COUNTY CODE OF ORDINANCES, AMENDING SECTION 36-31 PROVIDING AN EXEMPTION FOR REDEVELOPMENT TINY HOME DEVELOPMENTS; PROVIDING FOR CODIFICATION; PROVIDING FOR CONFLICTING PROVISIONS; PROVIDING FOR SEVERABILITY; AND PROVIDING AN EFFECTIVE DATE.
All interested parties are invited to attend the public hearings and to be heard. Copies of the proposed Ordinance and supporting information are available for inspection in the Planning Department, 96161 Nassau Place, Yulee, FL 32097. Comments may also be directed in writing to the Planning Department, e-mailed to planning@nassaucountyfl.com, or received by telephone at (904) 530-6320. All comments will become part of the record in this matter and subject to Florida’s public records law.
In accordance with the Americans With Disabilities Act, persons needing a reasonable accommodation to participate in this proceeding should contact the County Managers Office at contact@nassaucountyfl.com, 96135 Nassau Place, Suite 1, Yulee, FL 32097, Phone No. 904-530-6010, not later than seventy-two (72) hours prior to the proceeding. If you are hearing or voice impaired, please call the Florida Relay Service at 711 or toll free at 1-800-955-8771 (TTY).
THE PUBLIC IS INVITED TO BE PRESENT AND BE HEARD. IF A PERSON DECIDES TO APPEAL ANY DECISION MADE BY THE BOARD, AGENCY OR COMMISSION WITH RESPECT TO ANY MATTER CONSIDERED AT SUCH MEETING OR HEARING HE/SHE WILL NEED A RECORD OF THE PROCEEDINGS AND FOR THAT PURPOSE, MAY NEED TO ENSURE THAT A VERBATIM RECORD OF THE PROCEEDINGS IS MADE, WHICH RECORD INCLUDES THE TESTIMONY AND EVIDENCE UPON WHICH APPEAL IS TO BE BASED.
The Board of County Commissioners may continue hearings on this matter.
Klynt Farmer, Chair
Board of County
Commissioners
John A. Crawford,
Ex-Officio Clerk
FNL 1T 09-13-2023
#779671
-----------
BOARD OF COUNTY
COMMISSIONERS
NASSAU COUNTY, FLORIDA
INVITATION TO BID
NOTICE IS HEREBY GIVEN that the Board of County Commissioners of Nassau County, Florida invites sealed proposals for:
JAIL AND DENTENTION CENTER LAUNDRY EQUIPMENT PREVENTATIVE
MAINTENANCE AND REPAIR SERVICES
SOLICITATION NO.
NC23-019R
ELECTRONIC BIDS
RECEIVED UNTIL
SEPTEMBER 28, 2023 BY 10:00 AM
For detailed information regarding the due date and requirements for this solicitation, please visit the Nassau County website at https://pbsystem.planetbids.com/portal/49083/portal-home. Solicitation information and documents can be obtained free-of-charge via the County’s vendor portal.
ATTEST:
JOHN A. CRAWFORD
EX-OFFICIO CLERK
KLYNT FARMER
CHAIRMAN
BOARD OF COUNTY
COMMISSIONERS
NASSAU COUNTY, FLORIDA
FNL 1T 09-13-2023
#779789
-----------
Legal Notice:
ASSUMED NAME:
KATARZYNA BARBARA KUJAWA
PRINCIPAL PLACE OF BUSINESS:
2666B 1st Avenue
Fernandina Beach, FL 32034
NAMEHOLDER(S):
Katarzyna Barbara Kujawa
Kujawa Katarzyna Barbara
Katarzyna-Barbara:Kujawa, Bene, Auth, Rep
9-13-2023 and 9-20-2023
September 13, 2023 and September 20, 2023
FNL 2T 09-13-20-2023
#779476
-----------